AIDT Maritime Center HVAC Replacement Project

Sealed proposals will be received by Alabama Industrial Development Training until 10:00 AM on Thursday, September 10, 2026, at which time and place they will be publicly opened and read. A cashier's check or bid bond payable to Alabama Industrial Development Training in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.A Mandatory Prebid Meeting will be held at Alabama Industrial Development Training located on 360 Addsco Rd, Mobile, AL 36602 at 2:00 PM on Thursday, September 3, 2026. Drawings and specifications may be examined at the office of Watermark Design Group, 2970 Cottage Hill Road, Suite #200, Mobile, AL 36606, (251) 344-5515, F.W. Dodge Plan Rooms in Montgomery and Birmingham, CMD Group, Document Processing Center, 30 Technology Parkway South, Suite 500, Norcross, GA 30092-2912, and through SCAN.Bid Documents may be obtained from the Architect upon deposit of $50.00 per set, which will be refunded in full on the first set issued to each General Contract bidder submitting a bona fide bid and upon return of documents in good condition within ten days of bid date. Other sets for General Contractors, and sets for subcontractors and suppliers, may be obtained with the same deposit, which will be refunded as above, less cost of printing, reproduction, handling, and distribution. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted.

Agencia

Alabama Industrial Development Training

N° de solicitud

—

Tipo de aviso

Local Solicitation

NAICS

238220 — Plumbing, Heating, and Air-Conditioning Contractors

PSC

N045 — Installation Of Equipment- Plumbing, Heating, And Waste Disposal Equipment

Valor estimado (inferido, no oficial)

$28,405 – $252,187 (51 awards similares)

Set-aside

—

Lugar de ejecución

AL

Publicada

19 de ago de 2026

Cierre

10 de sept de 2026

Última actualización

—

¿Calificás como pequeña empresa? El tope de facturación o empleados para el NAICS 238220 lo define la SBA y cambia con el tiempo — lo más seguro es confirmarlo ahí, no acá. Verificar en sba.gov ↗

GovBidder Connect no es una agencia gubernamental. Esta información se agrega de fuentes oficiales de dominio público y puede tener demoras o errores. Verificá los datos en la fuente oficial antes de actuar.